Office renovation Assignment 2 [SOLVED]

Assessment 2

Table of Contents

Project charter 1

Literature review 3

Work breakdown structure 5

Schedule plan 5

Gantt chart 5

Milestones 7

Deliverables 8

Network diagram 8

Conclusion, findings and recommendation 8

References 10

Appendix 11

LIST OF FIGURES

Figure 1: Work breakdown structure 5

Figure 2: Network diagram with project task ID 8

Figure 3: Gantt chart 11


Project charter

Project name: Office renovationProject number: 1.0
Date: 10-03-2022Revision number: 1.0
Project goals Star-tech provides consultation services for digital transform. It wants to renovate office component such as conference hall and two staff rooms for furniture, acoustic panels, projector and other equipment to meet the business requirement. The project aims to deliver a quality-experience to guest and customers in conference room and add technical tools such as projectors for better presentation of the products and services.
Deliverables Design drawings Proposals Renovation as required Project documentation
Scope definition Project has three tasks in scope: installation of acoustic panels, furniture and technical equipment. It includes repaint on walls after changes in network infrastructure to ensure compatibility of new devices. It also provides related technical and non-technical items such as sofas and projector screens to deliver the intended features. However, it does not include any demolition and reflooring of the selected and other office area.
Project milestones Design blueprints Procurement request proposals Installation of new equipment Repainting and cleaning Project documentation and closure
Assumptions, constraints and dependencies It is assumed that the business manager and one employee is available to the project team to get assistance within time regarding any query. It is assumed that the project scope is not expanded to other areas and available cost and time is sufficient to meet the requirements. It is expected that the organisation is providing internal supports for resources and there are timely approvals and audits to lead performance (Heagney, 2016). The project is assumed to have no changes in requirement once the procurement of the material is received. It has constraints of time and cost because most of the project work cannot be managed in business hours due to disruptions in business operations. Cost is also limited and cannot be extended for the same deliverables (Meredith et al., 2017). It is a constraint that required quality of acoustic panels may not be available in local market due to limited number of resellers.
Project organisation structure Sponsor: business manager is acting as sponsor. The person has role to guide and monitor the project execution and outcome through decisions on various project designs and requests. Project manager: As a head of the project, the person aims to deliver the proposed outcome while ensuring optimised use of the capability and constraints to complete the project with team. Team members: These people work under contractor and project manager to accomplish the required tasks within quality criteria (Richardson and Jackson, 2018). Contractor: The person/ business finalised after request for proposal for procurement of various materials. A contractor has role to deliver specific features in the project such as repaint of the interior within given time.
Estimated cost Project has estimated cost of $50,000 considering estimated cost of materials ($35,000), cost of labour ($10,000) and overhead and miscellaneous cost ($5,000)
Risks and issues Following are major risks identified during initial investigation of the project and business case: Labour shortage and productivity issue Health and safety hazard Sub-contractor default Change orders Design error and omission
Related document The project includes request for order, site permits and approval letters as related document.
Project authorisation
Approved by: Business managerDate:
Approved by: Project managerDate:

Literature review

Classification of project life cycles

Project are accomplished using a certain pattern and such patterns are called life cycles. It is significant to determine the project life cycles to determine how the project can deliver the results. Project life cycles can be classified into three categories: predictive or fully plan-driven, iterative and incremental; and adaptive or agile (Heagney, 2016). In predictive life cycle, project constraints such as cost, time and scope are identified earlier and comprehensively. Later, project phases are created as breakdown of the work whereas project phases can be overlapping or sequential. Once project stages are identified, in-detailed project plan is created for the entire project and it is sometime referred as rolling wave planning or progressive elaboration (Richardson and Jackson, 2018). High-level plans are used to guide the execution but detailed planning is used for near future tasks. Predictive life cycle is an implementation of waterfall approach in project management.

Iterative and incremental life cycle also emphasises on breakdown of the project into phases where phases may be overlapping or sequential. In a comparison to predictive life cycle, scope is not determined ahead of the time and in detail. It only determines the scope for the first iteration and next scope is determine for new iteration (Crowder and Friess 2015). It focuses on basic functionality or minimum viability of the product in initial iteration and subsequent iterations are expanding scope and product features.

For complex projects, it is challenging to move with predictive approach because it creates constraint on change management and it may result in significant loss of time and resource capabilities. Iterative and incremental approach is closer to agile or adaptive approach but it lacks stakeholder engagement and dynamic change consideration. In adaptive project management, there is higher emphasise on rapid change and therefore, processes within an iteration also may be in parallel execution to deliver the outcome quickly. Adaptive approach determines scope for the current iteration but it ensures that iterations are more rapid to deliver rapid functional products (Layton et al., 2020). It breaks the scope into deliverables and prioritize them to deliver in short time period such as maximum of four weeks. At the end of iteration, customer and other stakeholders review the outcome and feedback is used to improve over the next iterations.

Phases of different project life cycles

In predictive life cycle, requirements are defined upfront before to start the development. It has constraint on change and key stakeholders are engaged only at specific milestones. Project execution depends on detailed plan created for eventual deliverables so that risk and cost are controlled for each task as per the plan. It has mainly five stages: analyse, design, build, test and deliver. Analysis stage is associated to conduct feasibility assessment of business and identify requirements. Design phase includes blueprints of the designs to consider for implementation. Build phase is dedicated to construct or code the requirements into deliverable form. Test phase validates the product against the customer requirement and changes are considered with re-initialisation of new life cycle for the change (Harrison and Lock, 2017). Final phase in life cycle is to document the project, provide training and support and close the contract.

Iterative and incremental phase has similar number of the phases. However, all the phases are within several iterations. For instance, all five stages are part of first iteration and same stages are also included in second and so on. Adaptive project management may have iteration-based or flow-based agile phases (Crowder and Friess, 2015). In iteration-based agile approach, project has several sprints to deliver features whereas initial iteration has role to plan and estimate execution to determine framework deliverables. Flow-based approach uses Kanban method in which iterations are used but work is not restricted to a particular iteration.

Apart of these, the project phases can be classified into two categories: sequential and overlapping. In sequential execution, next stage can be started only if ongoing/ previous stage is finished. In such phases, there is fewer opportunity to compress the schedule and optimise the resource utilisation. In overlapping phases, several phases can be started and execution in parallel. It allows better distribution of the resources and capabilities (Kerzner, 2018). However, it also demands adequate planning and increased number of resources in team.

Work breakdown structure

Figure 1: Work breakdown structure

Schedule plan

Gantt chart

Gantt chart has main purpose to represent time-constraint activities and associated resources and constraints such as deliverable, assigned resources and cost constraint (Harrison and Lock, 2017). The presented Gantt chart indicates that project has mainly six phases and each phase have several sub-tasks to accomplish. The project has mainly five milestones that needs to be delivered on time to ensure project can be completed within time.

Table 2: Project schedule

Task NameDuration in daysStartFinishPredecessors
Office renovation5710-03-2227-05-22
Initiation710-03-2218-03-22
Define goals210-03-2211-03-22
Create a business case214-03-2215-03-223
Complete project charter316-03-2218-03-224
List of stakeholders116-03-2216-03-224
Planning721-03-2229-03-22
Define scope221-03-2222-03-225
Create a budget baseline321-03-2223-03-225
Create project plan224-03-2225-03-229
Set roles and responsibilities228-03-2229-03-226,10
Design628-03-2204-04-22
Project schedule228-03-2229-03-2210
Design blueprint428-03-2231-03-225,10
Procurement strategy130-03-2230-03-2213
Testing strategy130-03-2230-03-2213
Resource allocation231-03-2201-04-2215
Change approval process104-04-2204-04-2217
Implementation3528-03-2213-05-22
Site permits528-03-2201-04-2210
Kick-off meeting104-04-2204-04-2220
Repositioning of existing materials205-04-2206-04-2221
Site cleaning305-04-2207-04-2221
Noise cancellation certain308-04-2212-04-2223
Demotion of unwanted construction813-04-2222-04-2224
Request for proposal104-04-2204-04-2220
Contact potential suppliers505-04-2211-04-2226
Finalise the supplier112-04-2212-04-2227
Contract for delivery313-04-2215-04-2228
Contract for carpentry work313-04-2215-04-2228
Installation of acoustic panels1018-04-2229-04-2230
Repaint1002-05-2213-05-2231
Installation of projector and other equipment718-04-2226-04-2230
Monitoring and control4004-04-2227-05-22
Track efforts and cost2004-04-2229-04-2220
Monitor project progress2002-05-2227-05-2231
Procurement validation213-04-2214-04-2228
Carpentry work quality check218-04-2219-04-2230
Installation quality check227-04-2228-04-2233
Completion929-04-2211-05-22
Handover deliverables129-04-2229-04-2239
Review deliverables102-05-2202-05-2241
Get approval on results303-05-2205-05-2242
Documentation306-05-2210-05-2243
Sign-off111-05-2211-05-2244

Milestones

The project has five milestones:

  • Complete project charter- 18-03-2022
  • Create project plan- 25-03-2022
  • Design blueprint- 31-03-2022
  • Installation complete- 26-04-2022
  • Sign-off- 11-05-2022

Deliverables

Table 3: Deliverables

Project phaseDeliverable
InitiationBusiness case and project charter
PlanningScope statement, cost estimation, project plan and stakeholder analysis
DesignGantt chart, design blueprint and documents contain strategies and process
ImplementationPermits, Contract copies and quality checklist
Monitoring and controlTest results
CompletionDocumentation, training material and contract copy

Network diagram

It is used to understand the sequence of the activities and determine critical path in the project. Critical path is a sequence of the longest path that consumes comparatively more time and resources in the project and can cause failures (Heagney, 2016). Network diagram shows that highlighted sequence of the activities is a critical path for the project and remaining are easy inflow activities.

Figure 2: Network diagram with project task ID

Conclusion, findings and recommendation

The presented project can be completed within time and cost considering project schedule and available resources. It is identified that the project has some critical activities and for that there is need of rescheduling, more resources or cost to ensure desired outcome. It is recommended to define role and responsibilities of the project resources so that desired outcome can be achieved within time. Also, it is recommended to conduct initial feasibility study and engage the stakeholders at milestone delivery date to meet acceptance criteria (Kerzner, 2018). It is recommended to use agile approaches throughout the project if there is availability of more resources because the project has constraint of time due to no disruption in routine business operations at workplace (Richardson and Jackson, 2018).

It is concluded that the project can help the organisation to renovate the office building within defined constraint. It is also concluded that project management tools such as Gantt chart and work breakdown structure can help to ensure systematic execution with optimisation of the capabilities.

References

Crowder, J.A. and Friess, S., 2015. Agile project management: managing for success.

Harrison, F. and Lock, D., 2017. Advanced project management: a structured approach. Routledge.

Heagney, J., 2016. Fundamentals of project management. Amacom.

Kerzner, H., 2018. Project management best practices: Achieving global excellence. John Wiley & Sons.

Layton, M.C., Ostermiller, S.J. and Kynaston, D.J., 2020. Agile project management for dummies. John Wiley & Sons.

Meredith, J.R., Shafer, S.M. and Mantel Jr, S.J., 2017. Project management: a strategic managerial approach. John Wiley & Sons.

Richardson, G.L. and Jackson, B.M., 2018. Project management theory and practice. Auerbach Publications.

Appendix

Figure 3: Gantt chart

Order Now

Get expert help for Office renovation Assignment 2 and many more. 24X7 help, plag free solution. Order online now!

Universal Assignment (February 28, 2026) Office renovation Assignment 2 [SOLVED]. Retrieved from https://universalassignment.com/office-renovation-assignment-2-solved/.
"Office renovation Assignment 2 [SOLVED]." Universal Assignment - February 28, 2026, https://universalassignment.com/office-renovation-assignment-2-solved/
Universal Assignment September 12, 2022 Office renovation Assignment 2 [SOLVED]., viewed February 28, 2026,<https://universalassignment.com/office-renovation-assignment-2-solved/>
Universal Assignment - Office renovation Assignment 2 [SOLVED]. [Internet]. [Accessed February 28, 2026]. Available from: https://universalassignment.com/office-renovation-assignment-2-solved/
"Office renovation Assignment 2 [SOLVED]." Universal Assignment - Accessed February 28, 2026. https://universalassignment.com/office-renovation-assignment-2-solved/
"Office renovation Assignment 2 [SOLVED]." Universal Assignment [Online]. Available: https://universalassignment.com/office-renovation-assignment-2-solved/. [Accessed: February 28, 2026]

Please note along with our service, we will provide you with the following deliverables:

Please do not hesitate to put forward any queries regarding the service provision.

We look forward to having you on board with us.

Most Frequent Questions & Answers

Universal Assignment Services is the best place to get help in your all kind of assignment help. We have 172+ experts available, who can help you to get HD+ grades. We also provide Free Plag report, Free Revisions,Best Price in the industry guaranteed.

We provide all kinds of assignmednt help, Report writing, Essay Writing, Dissertations, Thesis writing, Research Proposal, Research Report, Home work help, Question Answers help, Case studies, mathematical and Statistical tasks, Website development, Android application, Resume/CV writing, SOP(Statement of Purpose) Writing, Blog/Article, Poster making and so on.

We are available round the clock, 24X7, 365 days. You can appach us to our Whatsapp number +1 (613)778 8542 or email to info@universalassignment.com . We provide Free revision policy, if you need and revisions to be done on the task, we will do the same for you as soon as possible.

We provide services mainly to all major institutes and Universities in Australia, Canada, China, Malaysia, India, South Africa, New Zealand, Singapore, the United Arab Emirates, the United Kingdom, and the United States.

We provide lucrative discounts from 28% to 70% as per the wordcount, Technicality, Deadline and the number of your previous assignments done with us.

After your assignment request our team will check and update you the best suitable service for you alongwith the charges for the task. After confirmation and payment team will start the work and provide the task as per the deadline.

Yes, we will provide Plagirism free task and a free turnitin report along with the task without any extra cost.

No, if the main requirement is same, you don’t have to pay any additional amount. But it there is a additional requirement, then you have to pay the balance amount in order to get the revised solution.

The Fees are as minimum as $10 per page(1 page=250 words) and in case of a big task, we provide huge discounts.

We accept all the major Credit and Debit Cards for the payment. We do accept Paypal also.

Popular Assignments

Assignment Quantitative CASP RCT Checklist

CASP Randomised Controlled Trial Standard Checklist:11 questions to help you make sense of a randomised controlled trial (RCT)Main issues for consideration: Several aspects need to be considered when appraising arandomised controlled trial:Is the basic study design valid for a randomisedcontrolled trial? (Section A)Was the study methodologically sound? (Section B)What are

Read More »

Assignment Qualitative CASP Qualitative Checklist

CASP Checklist: 10 questions to help you make sense of a Qualitative researchHow to use this appraisal tool: Three broad issues need to be considered when appraising a qualitative study:Are the results of the study valid? (Section A)What are the results? (Section B)Will the results help locally? (Section C) The

Read More »

Assignment Topics

PS3002 Assignment TopicsDear studentsPlease choose one of the topics below. Please note that if you are repeating this subject, you cannot choose the same topic that you did previously in this subject.patellar tendinopathyinstability of the lumbar spinehamstring strainperoneal tendinopathyhip – labral tear.hip osteoarthritispatellofemoral instabilityankylosing spondylitisanterior cruciate ligament rupture (conservative management)quadriceps

Read More »

Assessment 2 – Report

Assessment 2 – Report (1200 words, 30%)PurposeTo demonstrate an understanding of the purpose and application of evidence-based dietary advice and guidelinesLearning objectives1.Review and analyse the role and function of macronutrients, micronutrients and functional components of food in maintaining health2.Understand digestion, absorption and metabolism of food in the human body and

Read More »

Assessment 2 – Individual Case Study Analysis Report

Southern Cross Institute,Level 2, 1-3 Fitzwilliam Street, PARRAMATTA NSW 2150 & Level 1, 37 George Street PARRAMATTA NSW 2150Tel: +61 2 9066 6902 Website: www.sci.edu.auTEQSA Provider No: PRV14353 CRICOS Provider No: 04078ªPage 1 of 16HRM201 Human Resources ManagementSemester 1, 2026Assessment 2 – Individual Case Study Analysis ReportSubmission Deadline: This Week,

Read More »

ASSESSMENT 2 BRIEF HPSYSD101 The Evolution of Psychology

HPSYSD101_Assessment 2_20240603 Page 1 of 7ASSESSMENT 2 BRIEFSubject Code and TitleHPSYSD101 The Evolution of PsychologyAssessment TaskAnnotated BibliographyIndividual/GroupIndividualLength2,000 words (+/- 10%)Learning OutcomesThe Subject Learning Outcomes demonstrated by successful completion of the task below include:b) Examine the significant figures, events and ideas present in the history of psychology.c) Identify and relate the

Read More »

Assessment 1 – Individual Case Study Analysis Report

HOS203 Contemporary Accommodation ManagementSemester 1, 2026Assessment 1 – Individual Case Study Analysis Report (10%)Submission Deadline: This Week, at 11:59 pm (Week 4)Overview of this AssignmentFor this assessment, students are required to analyse an assigned case study about hospitality industry relevant regulations and/or operational and accreditation failures of a hospitality organisation.

Read More »

Assessment Brief PBHL1003FOUNDATIONS OF HEALTH AND HEALTH CARE SYSTEMS

Assessment BriefPBHL1003FOUNDATIONS OF HEALTH AND HEALTH CARE SYSTEMSTitleAssessment 2 TypeEssay Due DateWeek 6 Monday 14 April 2025, 11:59pm AEST Length1000 words Weighting60% Academic IntegrityNO AI SubmissionUse Word Document – submit to Blackboard / Assessments Tasks & Submission / Assessment 2 Unit Learning OutcomesThis assessment task maps to the following Unit

Read More »

Assignment 4 – Intersection Upgrades and Interchange Station Design

CIVL5550: Civil Infrastructure DesignAssignment 4 – Intersection Upgrades and Interchange Station DesignDue: This WeekSubmission Instructions:1.Submit a report of approximately 10 pages, covering the following:Part 1: Intersection Upgrade Design•Propose upgrade schemes for two sign-controlled intersections and one signalized intersection•Use SIDRA to evaluate the performance of both the original and upgraded intersections•Use

Read More »

Assessment Brief 1

1 of 14Assessment Brief 1Assessment DetailsUnit Code Title NURS2018 Building Healthy Communities through Impactful PartnershipsAssessment Title A1: Foundations of Community Health Promotions ProjectAssessment Type ProjectDue Date Week 4, Monday, 22nd of September 2025, 11:59pm AESTWeight 40%Length / Duration 1200 wordsIndividual / Group IndividualUnit Learning Outcomes(ULOS)This assessment evaluates your achievement of

Read More »

Assignment 1 – Digital Stopwatch

Assignment 1 – Digital StopwatchThis assessment is an individual assignment. For this assignment, you are going to implement the functionality for a simple stopwatch interface as shown above. The interface itself is already provided as a Logisim file named main.circ . Your assignment must be built using this file as

Read More »

Assessment Background Country Profile

BackgroundCountry ProfileKiribati is an island nation situated in the central Pacific Ocean, consisting of 33 atolls2 and reef islands spread out over an area roughly the size of India (see Figure 1).i Yet, Kiribati is also one of the world’s smallest and most isolated country. A summary of Kiribati’s key

Read More »

Assessment 3: PHAR2001 INTRODUCTORY PHARMACOLOGY

PHAR2001 INTRODUCTORY PHARMACOLOGYAssessment 3: Case StudyASSESSMENT 1 BRIEFAssessment Summary Assessment titleAssessment 3: Case study Due DateThursday Week 6, 17 April at 11:59 Length•The suggested number of words (not a word limit) for the individual questions within the case study is as indicated at the end of each individual question. Weighting50%

Read More »

Assessment Module 1 Healthcare Systems Handout

Module 1Healthcare Systems HandoutGroup AgendasHealth Professionals: You got into health to help people. However, as an owner and operator of a multidisciplinary practice, you need to see many patients to cover the cost of equipment, technology, office and consumables, and pay your staff. The Medicare benefit doesn’t cover the rising

Read More »

Assessment 2 – Case study analysis 

Assessment 2 – Case study analysis  Description  Case study analysis  Value  40%  Length  1000 words  Learning Outcomes  1, 2, 3, 4, 5, 6, 7  Due Date  Sunday Week 9 by 23:59 (ACST)  Task Overview  In this assessment, you will choose ONE case study presenting a patient’s medical history, symptoms, and relevant test

Read More »

Assessment NURS2018: BUILDING HEALTH COMMUNITIES

NURS2018: BUILDING HEALTHCOMMUNITIES THROUGH IMPACTFULPARTNERSHIPSAssessment 1 Template: Foundation of Community Health Promotion projectOverall word count excluding the template wording (63 words) and reference list:Introduction to health issue:The case study, increase breast screening in Muslim women living in Broadmeadows,Melbourne, focuses on addressing the low participation rates in breast cancer screening amongMuslim

Read More »

Assessment EGB272: Traffic and Transport Engineering (2025-s1)

EGB272: Traffic and Transport Engineering (2025-s1)ashish.bhaskar@qut.edu.auPage 1 of 8Assessment 1A (15%) Cover PageIndividual component: 5%Group component: 10%You are expected to submit two separate submissions:Individual Submission (5%): Each student must submit their own individual report. Details of the individual report are provided in Section 3.1, and the marking rubric is in

Read More »

Assessment 3 – Essay: Assessment 3 Essay rubric

Unit: NUR5327 – Management and leadership in healthcare practice – S1 2025 | 27 May 2025Assessment 3 – Essay: Assessment 3 Essay rubricLearning Objective 5:Differentiate drivers forchange and proactively leadhealth professionalresponses to changing anddynamic environmentsFails toidentify aclear plannedchange ordoes not linkit to thestrategic plan.0 to 7 pointsIdentifies aplannedchange, butthe link

Read More »

Assessment 2 – Case study analysis 

Assessment 2 – Case study analysis  Description  Case study analysis  Value  40%  Length  1000 words  Learning Outcomes  1, 2, 3, 4, 5, 6, 7  Due Date  Sunday Week 9 by 23:59 (ACST)  Task Overview  In this assessment, you will choose ONE case study presenting a patient’s medical history, symptoms, and relevant test

Read More »

Assessment 1 PPMP20009 (Leading Lean Projects)

Term 1, 2025PPMP20009 (Leading Lean Projects)1Assessment 1 – DescriptionAssessment title Case study reportAssessment weight 40% of the unit marksReport length 3000 wordsMaximum 8 pages excluding references and appendicesReport format MS Word or PDFSubmission type IndividualSubmission due by Friday, Week 6Assessment objectiveThe purpose of this assessment item is to help you

Read More »

Assignment Maternity – Paramedic Management

Title-Maternity – Paramedic ManagementCase Study – Home Birth Learning outcomes1. Understand the pathophysiology and prehospital management of a specific obstetric condition.2. Develop a management plan for a maternity patient.3. Examine models of care available for maternity patients.4. interpret evidence that supports paramedic care of the maternity patient and neonate.5. Demonstrate

Read More »

Assignment Guidelines for Cabinet Submissions

Guidelines for Cabinet SubmissionsGENERALThe purpose of a Cabinet submission is to obtain Cabinet’s approval for a course of action. Ministers may not have extensive technical knowledge of the subject matter -and may have competing calls on their time. It is, therefore, important that Cabinet submissions are presented in a consistent

Read More »

Assignment Secondary research structure

Dissertation – Secondary Research – Possible Structure and Content GuideA front cover stating: student name, module title, module code, Title of project moduleleader, supervising tutor and word count.Abstract (optional and does not contribute to your word count)This should be an overview of the aim of the critical review, the methodology

Read More »

Assignment E-Business and E-Marketing

Module HandbookFaculty of Business, Computing and DigitalIndustriesSchool of Business(On-campus)E-Business and E-MarketingModule.2025-26􀀀Contents Module Handbook 1Contents 2Module Introduction 3Module Leader Welcome 3Module Guide 5Module Code and Title 5Module Leader Contact Details and Availability 5Module Team Tutors Contact Details and Availability 5Module Teaching 5Module Intended Learning Outcomes 5Summary of Content 6Assessment and Deadlines

Read More »

Assignment II: Computational Fluid Dynamics (CFD) Analysis of

CRICOS Provider 00025B • TEQSA PRV12080 1MECH3780: Computational MechanicsAssignment II: Computational Fluid Dynamics (CFD) Analysis ofGeneralised Cardiovascular Medical DevicesIntroduction:In this assignment, you will develop your CFD capability by analysing a benchmark casefrom a validation study sponsored by the U.S. Food & Drug Administration (FDA) and fundedby the FDA’s Critical Path

Read More »

LCRM301 Researching criminology

LCRM301 Researching criminology Worksheet 1 This worksheet will be disseminated to students in Week 3 and will assist them in the planning and development of the second assessment task: literature review. PART 1: Refining your topic The topic I am interested in is: I am interested in this topic because:

Read More »

ASSESSMENT TASK 2 – COURT APPLICATION

APPENDIX B: ASSESSMENT TASK 2 – COURT APPLICATION (30% OF FINAL MARK)General informationThis Assessment task is worth 30 marks of your final mark.The task is either making (Applicant) or opposing (Respondent) an application before the Supreme Court in your respective state based on a fact scenario, which will be uploaded

Read More »

Can't Find Your Assignment?